Sne Engineering Co Ltd v. Chim Kee Machinery Co Ltd
Read the full judgment text of HCA 2025/2012 on BabelCite. This High Court CFI judgment was delivered on 24 March 2016.
1. The background to this case concerns a construction contract for the removal of H‑piles and bored piles at site near the Nam Cheong MTR station which was essential preparatory work prior to the boring of an underground tunnel being part of the MTRC’s construction of the Express Rail Link from Kowloon to the Mainland border.
Cites 2 cases
|
HCA 2025/2012 IN THE HIGH COURT OF THE HONG KONG SPECIAL ADMINISTRATIVE REGION COURT OF FIRST INSTANCE ACTION NO 2025 of 2012 __________________
__________________
________________________ J U D G M E N T 1.The background to this case concerns a construction contract for the removal of H‑piles and bored piles at site near the Nam Cheong MTR station which was essential preparatory work prior to the boring of an underground tunnel being part of the MTRC’s construction of the Express Rail Link from Kowloon to the Mainland border. 2.The removal of such piles required special expertise and heavy machinery. 3.The particular contract which sets the scene for this litigation is contract no 802. “802” referred to a site where the MTRC had awarded the main contract to Hsin Chong Construction Company (“HC”). HC had in turn sub‑contracted the plaintiff (“SNE”) to carry out the pile removals under sub‑contracts 8664/10 and 8800/11. Both are dated 11 March 2011 but the work had commenced before that date. 4.In order to carry out the works SNE needed to hire machinery and labour. They engaged the defendant, Chim Kee Machinery Co Ltd (“Chim Kee”) for this purpose. This contractual relationship commenced in September 2010. 5.There is not one overall contract between SNE and Chim Kee for this purpose, rather it is represented by a series of dealings recorded by a number of rental quotations, followed up by invoices and oral agreements. For the purpose of this litigation, they are referred to as the Machinery Hire Agreement (“MHA”), of which there are hundreds between 21 September 2010 and 25 May 2012. 6.The relationship between these two parties under the MHA is the core issue in this case. Other issues have arisen, largely after the purported termination of the MHA on 3 July 2012. They can be summarized by reference to SNE’s claims in these proceedings which are:
7.Additionally, there is an allegation of a conspiracy between HC and Chim Kee to disadvantage SNE. On 17 February 2016, less than two weeks prior to the commencement of this trial, SNE made an application to To J to join HC as a 2nd defendant and serve a much amended statement of claim alleging the tort of conspiracy, with detailed particulars which had not hitherto been pleaded. It was acknowledged that had the application been granted, it would have led to the inevitable adjournment of this trial with costs. The application was refused but the claim remains albeit pleaded with sparse particulars. Chim Kee relies both on inadequate pleading and on the facts in its strenuous denial of the conspiracy claim. ISSUES 8.Mr Billy K Y Kwan, counsel for SNE, and Mr Ian Pennicott SC with Joseph Wong, both counsel for Chim Kee, have helpfully provided a list of issues. They are not identical but may be summarized as follows:
WITNESSES 9.Six factual witnesses, three for SNE and three for Chim Kee, were examined and cross‑examined. SNE called a site engineer (Mr Ho Tik Sang), a construction supervisor (Mr Wong Chung Wai) and SNE’s general manager and associate (Mr Takuya Matsumoto). Mr Matsumoto explained that SNE was a Hong Kong joint venture company with Japanese partners, incorporated on 7 June 2010 for the specific purpose of tendering for the Express Rail project. The Japanese partners had the necessary expertise in pile extraction works. 10.Chim Kee called HC’s project manager (Mr Frankie Lam), their own managing director (Mr James Tang) and a crane operator (Mr Chung Yui Tung). 11.Collectively, their witness statements totalled approximately 160 pages without exhibits (of which Mr Matsumoto’s was 100 pages) and 816 pages with exhibits. The witness statements stood as evidence‑in‑chief. DISCUSSION 12.Nine areas of dispute require a determination. By dealing with them in a logical sequence the court’s decisions on the first two issues significantly impact on the resolution of some, but not all, of the later issues. (1) The terms of the MHA 13.Following the evidence given in court, there was no longer a serious dispute as to whether or not the “General Conditions of Hire” formed part of the MHA. Clearly they did. The Rental Quotations expressly referred to them and stated that they were available “upon request”. Moreover, they were attached to the Rental Agreements. The terms which are at the heart of the dispute are those concerning “payment” and “termination”. 14.The Rental Agreement payment is said to be “within 30 days against invoice date”. Clauses 4 and 5 of the General Conditions state:
15.It should be remembered at the outset that the contract between SNE and Chim Kee was a self contained contract for the hire of heavy plant and machinery on a construction site. The parties’ respective liabilities under the contract did not depend on SNE’s performance under its sub‑contracts with HC or indeed with HC’s contract, as main contractor, with the MTRC. Chim Kee supplied machinery and labour. SNE agreed to pay the hire charges within 30 days of each invoice. (Chim Kee does not rely on the “10 day” provision in Clause 4 above, as that was, as a matter of law, superseded by the “30 day” provision in the Rental Agreements.) 16.In a nutshell, SNE submits that the 30 day term did not apply. SNE submit that it was both waived by conduct between the parties and varied by a tri‑partite Rental Arrangement involving SNE, Chim Kee and HC entered into on 26 May 2012. These issues of “waiver” and “variation” require individual consideration. If the payment terms had been waived and/or varied, then SNE submits that Chim Kee’s termination of the MHA contract on 3 July 2012 was unlawful. 17.Whether or not it was unlawful largely turns on the court’s decision on the waiver and variation issues. Waiver? 18.The Rental Agreement commenced in September 2010. SNE’s case is based on the fact that for the next 15 months, at least, Chim Kee did not insist on strict compliance with the 30 day term. It is a fact that the 30 day term was never complied with. SNE points out, and Chim Kee does not challenge, that the average delay in payment for the monthly payment requests was 78 days up to early 2012. SNE even claims that there was an oral agreement (although it is not pleaded) that “2 – 3 months” was agreed. Chim Kee denies this. The question simply is whether or not the 2010 – 2011 acceptance by Chim Kee of late payments constitutes a waiver by conduct of the 30 days provision which estops Chim Kee from relying on it. 19.There is substantial agreement between the parties as to the law on this issue. They do not agree on its application to the facts. 20.Chitty on Contracts (32nd edition) states:
21.Mr Pennicott for Chim Kee places further reliance on a citation from Persimmon Homes (South Coast) Ltd v Hall Aggregates (South Coast) Ltd[2009] NPC 118 (UK Court of Appeal):
22.On the facts, Mr Kwan for SNE relies on the fact of late payments throughout 2011, the fact that the first written demand arising out of late payments was only made in December 2011, the fact of a flexible arrangement and the claim of an oral agreement to that effect. 23.On the other hand, as evidence that there had clearly been no “unequivocal representation” by Chim Kee, Mr Pennicott relies on:
24.Considering all the evidence on this issue, of which the above is a mere summary, it cannot be said that Chim Kee had agreed to waive the 30 day provision in substitution for a more flexible ill‑defined alternative. It is not open to SNE to translate Chim Kee’s patience as the basis of a change in the terms of the parties’ written agreement. At its highest, it was an indulgence by Chim Kee during 2011 which falls far short of an “unequivocal representation”. Variation 25.In support of their submission that there had been a variation of the payment terms, SNE primarily relies on the “Tri‑partite Rental Arrangement” dated 23 May 2012. 26.The background to this “TRA” can be briefly stated. Due to the difficulties being encountered by SNE in the pile extraction work, resulting in reduced payments from HC, it was agreed that SNE, HC and Chim Kee should consider the possibility of direct payments from HC to Chim Kee for the hire charges of machinery. 27.An “Arrangement” was reached as follows:
28.Mr Kwan submits that under this arrangement it was agreed that the payment obligation could be enforced against and discharged by either SNE or HC and that it contemplated settlement of invoices may take longer than 30 days. In such circumstances, the terms of the MHA had been varied and substituted with new and different terms. 29.However, in my judgment, SNE’s contention that the TRA constitutes a variation of contract must fail. An alternative payment method or a “second string to the bow” or a “safety net” it may be, but a substitution of new terms for old it is not. 30.The requirements for a contractual variation are the same as for a contractual formation. In this instance I find lacking any consideration from SNE to Chim Kee. Any consideration that there may be flows from HC, namely their contribution to the new alternative payment method. More importantly, the primary obligation to pay Chim Kee remained on SNE. 31.Post‑TRA events support this. By a letter of 26 June 2012 SNE requested HC to pay it (SNE) the May 2012 invoices which it undertook to pay on to Chim Kee (which, in fact, it never did). Thus, SNE did not regard itself as being relieved of its payment obligations under the MHA. 32.The fact that the payment terms were neither waived nor varied does not provide the whole answer to the question whether or not the termination on 3 July 2012 was lawful or not. A more detailed consideration of the events leading up to the termination is necessary, to which I now turn. (2) Was the termination of the MHA lawful or unlawful? 33.Chim Kee’s termination letter of 3 July 2012 is as follows:
34.This followed an earlier letter dated 26 June 2012 stating:
35.Between 8 December 2011 and termination, Chim Kee had written a total of eight letters (referred to, in part, at paragraph 23 above) concerning payment defaults, including a Statutory Demand for $10,399,066 on 3 April 2012. 36.On 17 May 2012, SNE paid the January and February invoices. 37.After the TRA at the end of May, a sum of $7.6 million was paid, understood to be for the March and April invoices. 38.As at 3 July, $4,993,916 was outstanding for pre‑June invoices. This plus the June invoices remains unpaid. The total amount claimed under this heading in the Statement of Claim is $8,884,574.50. 39.Obtaining payment from SNE had proved difficult. It seems that SNE were taking for granted Chim Kee’s patience and indulgence throughout 2011. However, no doubt Chim Kee’s anxieties about slow or non‑payment were heightened by the increasing complaints (rightly or wrongly) being made by HC (and MTRC) about SNE’s performance over the 1st half of 2012. SNE’s payment history strongly suggested that the worse the progress got the greater the risk of Chim Kee not getting paid. Hence the 3 July 2012 termination letter refers not just to an outstanding amount but to the fact that SNE “fails to provide any commitment on payment …” and the 26 June letter referred to “due to the past experience for pending issues …”. 40.The next day, on 27 June, SNE terminated, for reasons which were not made clear, its contract for labour with a company named Triangular Force. With diminished labour, work on site further deteriorated with the natural consequence of more risk of non‑payment to Chim Kee. 41.In my judgment, on the whole of the evidence, SNE has not been able to demonstrate, on a balance of probabilities, that Chim Kee’s termination was anything other than a valid exercise of their right to terminate the MHA pursuant to Clause 5(b) of the General Conditions of Hire. 42.The invoices claimed by Chim Kee for May and June total $7,986,827. The balance, ($8,884,574 − $7,986,827 = $897,747) relates to pre‑May outstanding amounts. The amounts certified by SNE for May and June total $6,449,193. I propose to take a median figure (($7,986,827 + $6,449,193) ÷ 2) namely, $7,218,010 and add the pre‑May figure of $897,747 = $8,115,757. 43.On 11 July, SNE informed HC that they had accepted Chim Kee’s termination. This was but one event in a period between 3 July and 26 July which Mr Pennicott described as a period of “chaos”. Regardless of the lawful termination, as found, three issues stemming from this period of chaos remain. They are:
44.SNE has quantified its damages under (ii) above in the sum of $1,575,934 and under (iii) $1,330,691. (3) Should the MHA include an implied term? 45.SNE’s claim for the above sums depends on the incorporation of an implied term that Chim Kee shall not obstruct or cause delay to SNE’s works unreasonably during and after the termination on the MHA. Two questions arise, first, should such a term be implied and secondly, if so, does it still operate after the termination of the contract? 46.The express terms of the MHA are confined to terms relating to the machinery, not labour. This implied term clearly is directed at the conduct of the workforce. The classic five point test is (in short) (i) reasonable and equitable? (ii) necessary for business efficiency? (iii) obvious? (iv) capable of clear expression? and (v) does not contradict any express terms? This test has been recently condensed by Lord Hoffman to a single question in Attorney General of Belize v Belize Telecom Ltd [2009] 1 WLR 1988 at [21]:
47.I am persuaded that such a term may be incorporated as contended for by Mr Kwan. More difficult however is the second question, namely, whether it can operate after the contract has been terminated. 48.In my judgment, all contractual relations between SNE and Chim Kee were terminated on 3 July 2012. Mutual rights and obligations ceased, including the implied term. The implied term could have been relied on by SNE up to 3 July but not after. 49.As a matter of common sense, if Chim Kee had caused loss to SNE after 3 July by deliberate obstruction, there would be a cause of action, possibly trespass, under which they could be compensated for Chim Kee’s wrongful acts. However, I cannot agree that the cause of action would be the breach of a term in a contract for hire of machinery which had come to an end. 50.As will be seen below, the issue becomes academic as result of my evaluation and assessment of the evidence relating to this “chaotic” three week period. (4) Damages for deliberate slow operation of machinery from 3 July 2012? and (5) Damages for Chim Kee’s failure to remove its machinery after 11 July 2012? 51.These two issues may be considered together and resolved on the facts. During the relevant period, little or no pile extraction work was done, meetings between SNE, Chim Kee and HC were held to discuss matters and propose solutions, many letters were exchanged, there was a short labour strike on 5 July and on 25 July SNE was granted an ex parte injunction ordering Chim Kee to remove machinery (which turned out to be an unwise move as it was later, at an inter parties hearing, discharged with costs against SNE). 52.Having heard the witnesses, I find the following facts to have been proved. 53.By a letter dated 3 July 2012, HC took over SNE’s sub‑contracts works saying:
54.That this occurred on the same day as the termination of the MHA is not a sinister co‑incidence, rather it was commercial common sense by HC. It was the culmination of repeated complaints about poor performance (again, rightly or wrongly) coupled with the fact that, as of 3 July, SNE was without a hiring agreement for plant and machinery. 55.A period of uncertainty followed. For the next two days, HC gave the instructions on site. On 6 July, a meeting took place between representatives of SNE, Chim Kee and HC and lawyers for SNE. SNE later claimed an agreement had been reached that Chim Kee would hire the machinery to them for a further three months. This was immediately denied by Mr James Tang in an email. Mr Kwan submits that the email is “equivocal”. I do not agree. It states:
56.Chim Kee’s agreement was to “stand by”. This they did under SNE’s instructions until 11 July, the day on which SNE “accepted” that the MHA had been terminated. 57.Thereafter, between 11 and 26 July, the main dispute concerned the responsibility for and correct procedure for the demobilization of the site. By this time, any remnants of good‑will between the parties had evaporated. There were two bones of contention. Chim Kee’s position was that by the very nature of the very large and heavy machinery involved, it was SNE’s responsibility to provide a demobilization schedule or plan. Demobilization was not a straightforward task of driving away all the plant in a day or so to another place. Secondly, it was Chim Kee’s position that any such removal plan required the consent and approval of HC and the MTRC engineer. 58.SNE disagrees with both of the above. Comparisons were drawn between the site in question (“802”) and another MTR site at “820”. At 820, it was said, earlier in the year the site was demobilized without such requirements. I agree with Mr Tang for Chim Kee that such comparisons do not assist. The evidence revealed that 820 was a significantly smaller site, the main contractor was different and the demobilization was the simple consequence of the works there having been finished. All in all, it was a significantly different situation. 59.As for the issue of “consent”, Chim Kee points to Clause 91.6 of the main contract between MTRC and HC which states:
60.SNE’s answer is that this clause does not bind Chim Kee and moreover the “contractor’s equipment” does not include Chim Kee’s equipment. “Contractor’s equipment” being defined in the main contract as:
61.SNE submits that Chim Kee’s equipment cannot fall within the definition of “contractor’s equipment” under the main contract. 62.Shelving for a moment the niceties of this argument, MTRC’s and HC’s actual stated position at the material time should not be overlooked. 63.By a letter of 17 July 2012 of SNE, HC stated:
and on 20 July:
64.That SNE’s position bears the hallmarks of an afterthought is supported by their own letter of 3 July when, at the beginning of the three week chaos, they stated:
65.Following the ex parte injunction on 25 July, the MTRC made its own position clear by letter to HC on 27 July:
66.To sum up, whilst it is difficult to be certain about issues in this period when uncertainty prevailed, I have come to the conclusion that, on the balance of probabilities, it was reasonable of Chim Kee to require a demobilization plan and it was reasonable to require the consent of HC and the MTRC engineer. SNE have not satisfied me that any damages suffered (whatever the cause of action may be) arising from the events of 4 – 26 July are Chim Kee’s liability. 67.There are two final matters to be noted under these headings. 68.First, it is difficult to understand the evidential basis of the quantum of SNE’s two claims in this regard ($1,575,934 and $1,330,691). No evidence has been advanced, written or, for example, from an in‑house quantity surveyor explaining them. The figures appear on a piece of paper annexed to Mr Matsumoto’s witness statement but it is doubtful that he is truly able to “prove” them. 69.Secondly, part of Chim Kee’s counterclaim includes a claim for rental payments for machinery actually used by SNE during this period, namely up to 27 July 2012 being the date when HC entered into an agreement with Chim Kee to take over the rentals and use them themselves in carrying out the works it had taken over from SNE the same day. The amount of this claim is $3,309,306 (the July 2012 invoices). 70.In his final submission, Mr Pennicott made a conditional concession. He conceded that in view of the chaotic nature of the events and the uncertainties prevailing at the time, it might be considered difficult to pursue this claim with any enthusiasm. He also proposed that the quid pro quo of this concession should be that SNE should take a similar stance in respect of its claims during the same period. 71.Albeit an admirable proposal, SNE were not inclined to agree. The court, however, has reached the same outcome as that proposed by Mr Pennicott, albeit by a somewhat longer route. There will be no damages awarded to either party arising out of the events between 4 and 26 July 2012. (6) Had SNE overpaid Chim Kee for rental charges under the MHA prior to 3 July? 72.Chim Kee’s receipts for the hire of machinery was calculated by reference to its “work bills”. No complaint was made about this method during the contract. 73.Since the termination of the contract, SNE has done its own alternative calculation as a result of which it claims to have overpaid Chim Kee a total sum of $3,815,330. The data relied on for this claim are the “palm print records”. These record when a worker enters and leaves the site. 74.The work bills were a record of the start time and the finishing time that a particular machine was in operation. Each day they were signed and countersigned by Chim Kee and SNE representatives. 75.The “palm prints” recorded the time a labourer was on site. 76.Thus, the key difference between the two methods was that the work bills recorded the machine’s time of work, the palm prints recorded the labourer’s time at work. 77.In my judgment, SNE’s claim cannot succeed for the following combined reasons:
78.The palm print claim seems clearly to be another post‑termination afterthought, fuelled by a sense of grievance and designed to make inroads into the outstanding hire charges which were unquestionably due in excess of $8 million. (7) Detention of SNE’s property at the Fanling Workshop 79.This is a discrete item unaffected by other issues. 80.SNE and Chim Kee had a “storage agreement” for keeping some of SNE’s heavy equipment at a workshop in Fanling. It is agreed that the agreement was terminated on 1 March 2012. 81.SNE’s first request to collect their equipment was on 9 July 2012, shortly after the termination of the MHA. The general lack of good‑will contributed to the fact that an impasse developed. It was not until three months later that two joint inspections took place on 12 and 19 October 2012. That did not resolve the matter either. Chim Kee said they would empty the workshop on payment of $50,000 “lifting” fees. SNE said this was excessive and proposed a charge of $4,800 being the hire charge of one crane for one day. Chim Kee’s alternative offer was that SNE arranged its own collection, conditional upon the provision of an indemnity against injury or loss. SNE considered this to be unreasonable. 82.As for the “lifting” fee of $50,000, such evidence as there was tends to support the contention that it was not unreasonable. SNE’s counter‑offer took no account of labour. Also, on a previous occasion a fee of $37,500 had been paid without demur for a similar exercise over three days. This particular task at Fanling, according to Mr Tang, would have taken more than three days. Moreover, there was written evidence that a Mr Lee, of SNE, had agreed the $50,000 fee. 83.However, insisting on an indemnity was unduly obstructive. After all, it would have been SNE’s own staff collecting their own equipment. The risk of loss and damage to Chim Kee was negligible. It was an unnecessary restriction on progress being made. The matter remained unresolved. In 2013 Mr Tang increased the “lifting” fee to $100,000 because, he explained, he was “fed up and angry”. Whether or not the anger was justified it serves to demonstrate the continuing lack of good‑will and co‑operation. 84.In short, I disallow Chim Kee’s counterclaim, for charges since October 2012 (assessed at $820,000, a high sum due to the fact that many of these abandoned items are still at Fanling) but I am not satisfied either that SNE have made out a claim for loss arising out of their inability to use this equipment in storage. 85.SNE’s claim under this heading is $660,250. This is said to be the cost of renting alternative equipment from its Japanese suppliers. However, Mr Matsumoto agreed that SNE had not paid any of the invoices which made up the substantial part of the $666,280 claim. In the absence of any other evidence as to quantum their claim is dismissed. 86.Chim Kee is entitled to storage charges from March to October 2012. $70,000 a month was charged under the original storage agreement terminated in March. The exact figure claimed has been reduced to $387,900. The nature of their claim is such that the court feels entitled to take a broad brush approach to take account of the fact that it was unclear exactly what equipment remained and for how long. I regard $250,000 as a fair and equitable sum of the period up to October 2012. (8) Lost or damaged items belonging to Chim Kee but not returned to them by SNE 87.This is part of Chim Kee’s counterclaim and concerns two sets of casings, two guard houses and one soil tank. Chim Kee’s case is that after termination of the MHA, one set of casings was returned but damaged beyond repair, the other set was not returned. The guard houses were not returned. The soil tank was returned but badly damaged. 88.SNE’s site manager, Mr Ho Tik Sang, gave evidence about these items. He said that the inventory record dated 30 September 2012 included two guard houses which had been on site 802 both before and after 3 July 2012. SNE’s workers had no opportunity to physically return them after 3 July. The evidence on the guard houses is unclear and Chim Kee has failed to establish its claim on a balance of probabilities. 89.The soil tank was returned. Chim Kee claims it was damaged beyond repair. Mr Ho said its condition was as a result of fair wear and tear. In the absence of further particulars, it is not possible to assess its true condition. The claim is not made out. 90.One of the two sets of casings was, according to Mr James Tang, recovered from site 802 in December 2013. Again, he said it was damaged beyond repair. Again, I regard this as insufficient evidence of its condition without further particulars. It had presumably been on site 802 ever since July 2012, a place to which SNE had had no access since then. What happened to it between July 2012 and December 2013 is not known. Chim Kee’s claim for its replacement value in excess of $2 million, in these circumstances, cannot succeed. 91.As for the second set of casings, which Chim Kee says has not been returned, SNE relies on Mr Ho’s evidence which was that both sets of casings were on site at the time of the joint inspection on 30 July 2012. Given that all plant, machinery and equipment, the property of Chim Kee, was brought onto site for use by SNE, and given that they left the site in July 2012, I do not regard it as “more likely than not” that they either deliberately or inadvertently took the casings with them. It is not reasonable in all the circumstances to lay at SNE’s door the fact that it may have gone missing. (9) The conspiracy claim 92.This issue has been left to the last for good reason, namely that in view of the court’s findings hitherto it can be dealt with fairly briefly. 93.Even if the court had found that the termination of the MHA on 3 July 2012 had been unlawful, the followings findings remain valid. 94.SNE’s two sub‑contracts with HC were terminated by HC in September 2012 — over two months after the termination of the MHA. SNE’s pleaded particulars of loss under this heading are:
95.However, no such costs have been paid by SNE to HC. On the contrary, SNE would claim (and may do so in other proceedings) compensation against HC for breach of the two sub‑contracts. 96.As against Chim Kee, the claim depends on there being a causal link between the MHA termination in July and the sub‑contracts termination in September and conspiracy. 97.It is convenient to deal with this issue on the following analysis of the conspiracy claim. It is pleaded as follows:
98.Allegations of conspiracy must be carefully and specifically pleaded. Ma CJHC in Pido v Compass Technology Co Ltd [2010] 2 HKLRD 537 stated a pleading must contain the following:
99.It is plain that the single paragraph pleaded does not comply with these requirements. With this in mind, it is not surprising that SNE applied to amend its pleadings (two weeks before the trial as earlier referred to) but without success (also not surprisingly). 100.However, the conspiracy allegation fails not only on the pleading deficiency but also on the facts. 101.A number of matters have coalesced in the mind of SNE based on a sense of grievance and resulting in a conspiracy theory. Those matters include:
102.Mr Kwan, in his helpful final written submissions under the heading of the conspiracy issues, in a two‑page paragraph asks, inter alia, about 20 questions for the court to consider. I assume he would describe them as rhetorical questions in the sense that they should answer themselves. 103.It is a common feature of a conspiracy theory that it throws up more questions than answers. In my judgment, his questions do not answer themselves, rather they highlight the questions to which there are opposing answers, which have largely been the subject of the disputes in this action. Twenty questions, rhetorically posed or otherwise, do not convert a conspiracy theory into a conspiracy reality. 104.The following matters, which I find to be facts having considered the evidence, serve to illustrate not that a conspiracy was being hatched but rather a serious problem requiring urgent resolution was developing:
105.For the above reasons, SNE’s conspiracy claim cannot succeed, whether or not the termination of the MHA was lawful. 106.Finally, the court also notes under the general heading of “even if …” that SNE’s evidence of losses actually suffered, and in what amounts, was deficient. Even if liability had been established for unlawful termination, overpayments, conspiracy etc, SNE did not, on its own evidence, discharge the burden of proof on it to properly establish that it had actually suffered a loss or the amount of any such loss. It is acknowledged that this is a very generalized criticism. However, in view of the court’s findings it need be no more. ORDER 107.On the plaintiff’s claim, there will be judgment for the defendants with a costs order nisi against the plaintiff, to be taxed if not agreed. 108.On Chim Kee’s counterclaim, there will be judgment for the defendant in the sum of $8,365,757 plus interest at 1% over HSBC base rate from 1 August 2012 on the sum of $8,115,757 (paragraph 42 above) and from 1 November 2012 on the sum of $250,000 (paragraph 86 above) to the date of judgment, and thereafter at judgment rate until payment, together with a costs order nisi in the defendant’s favour, to be taxed if not agreed. If necessary, I grant a certificate for two counsel.
Mr Billy K Y Kwan, instructed by Leung & Associates, for the plaintiff Mr Ian Pennicott SC, leading Mr Joseph Wong, instructed by Tsui & Co, for the defendant |
Cases cited in this judgment
Further hearings and rulings under HCA 2025/2012