Sne Engineering Co Ltd v. Chim Kee Machinery Co Ltd
Read the full judgment text of CACV 101/2016 on BabelCite. This Court of Appeal judgment was delivered on 11 July 2017.
1. The action below, featuring both claims and counterclaims, arose out of the arrangements between the plaintiff (“ SNE ”) and the defendant (“ Chim Kee ”) for the hire of machinery (sometimes inclusive of operators) for pile removal works at a construction site for the Express Rail Link. The trial judge, Deputy High Court Judge Burrell, dismissed all of SNE’s claims and gave judgment for Chim Kee on two of its counterclaims. SNE now appeals to this court and Chim Kee cross‑appeals.
Cited by 1 case · Cites 6 cases
|
CACV 101/2016 IN THE HIGH COURT OF THE HONG KONG SPECIAL ADMINISTRATIVE REGION COURT OF APPEAL CIVIL APPEAL NO 101 OF 2016 (ON APPEAL FROM HCA NO 2025 OF 2012) ____________
____________
_________________ J U D G M E N T _________________ Hon G Lam J (giving the judgment of the Court): I. Introduction 1.The action below, featuring both claims and counterclaims, arose out of the arrangements between the plaintiff (“SNE”) and the defendant (“Chim Kee”) for the hire of machinery (sometimes inclusive of operators) for pile removal works at a construction site for the Express Rail Link. The trial judge, Deputy High Court Judge Burrell, dismissed all of SNE’s claims and gave judgment for Chim Kee on two of its counterclaims. SNE now appeals to this court and Chim Kee cross‑appeals. II. Background The project 2.The construction of the Express Rail Link by MTR Corporation Ltd (“MTRC”) involved various sections of tunnel and underground works. As the path of the rail line went through areas with pre‑existing foundation piles in the ground, it was necessary to remove certain H‑piles and bored piles at various sites to allow the tunnel boring machine to operate. One such site was situated near the Nam Cheong MTR Station, called Site 802. 3.The main contract (no 802) for the removal of underground piles at Site 802 was awarded to Hsin Chong Construction Co Ltd (“Hsin Chong”) in January 2010. Hsin Chong entered into two sub‑contracts with SNE both dated 11 March 2011 (nos. 8664/10 and 8800/11), for the removal of bored piles and H‑piles respectively, although works had begun as early as September 2010. SNE in turn contracted with Chim Kee (among others) to hire the necessary machinery (sometimes inclusive of operators) to carry out the works under the sub‑contracts. The equipment supplied was heavy machinery such as rotators, crawler cranes, truck cranes, casings and tools, sometimes with operators. 4.There was another site, known as Site 820, where the main contractor was Dragages‑Bouygues JV, for which SNE was also the sub‑contractor. Likewise, SNE hired machinery (sometimes inclusive of operators) from Chim Kee to carry out the necessary works. The machinery hire arrangement 5.Although described in the judgment below as the Machinery Hire Agreement (“MHA”), it was common ground that the hire arrangement took the form of many separate agreements for the hire of individual machines. In a few cases there was a document called rental agreement for a particular machine, but in most cases there was simply a rental quotation. There was no one overall written supply contract between the parties. The dealings were relatively informal, with oral discussions followed by written quotations from Chim Kee to SNE. Some of the quotations were signed by SNE but some were not or were only signed after the machinery had been delivered. 6.The quotations recorded the equipment rented, the project in question (eg 802 or 820 as the case may be), and the rates for each item including overtime rates for workers where relevant. Some quotations also stated a minimum hire period such as one month or two months. The quotations (mostly) specified the payment term as “Within 30 days against invoice date” or (in some cases) “payment against invoice” depending on the type of machines. Each of the quotations contained a statement:
The General Conditions of Rental Agreement of Chim Kee were identical to another set of terms called “General Conditions of Hire”. The judge found that they were incorporated as part of the machinery hire agreements. There is no appeal against this finding. These conditions included the following:
7.Chim Kee began issuing invoices to SNE in November 2010. From the start many invoices were paid more than 2 months and sometimes 3 months later. SNE argued at trial that this gave rise to a waiver by Chim Kee of the payment terms in the quotations but this was rejected by the judge.[1] There is no appeal against this finding. 8.It appears that from fairly early on in the course of the sub‑contracts with Hsin Chong, SNE had encountered cash flow problems. SNE said this was caused by more adverse ground and pile conditions than originally contemplated and put the blame on Hsin Chong for not passing on to SNE any of the additional payment Hsin Chong obtained from MTRC. The responsibility for the difficulties is not relevant for the purposes of this appeal. What the problems led to was the involvement of Hsin Chong in making direct payment to Chim Kee of some of its invoices issued between March and December 2011 (as well as to a supplier of labour to SNE called Triangular Force). Despite this, SNE continued to have cash flow problems and amounts owed to Chim Kee were accumulating. By the end of the first quarter of 2012, Chim Kee had become quite concerned about the outstanding invoice sums. Events leading to the TRA 9.On 30 March 2012, following a meeting with SNE, Chim Kee wrote to request SNE to certify the payment amount up to date and confirm the payment schedule, saying “we need your payment to run our service, if you cannot settle the payment, we have no alternative but to stop our service”. Within days, Chim Kee served a statutory demand on SNE for $10,399,066 being outstanding rentals calculated apparently up to February 2012. 10.On 11 April, SNE responded and proposed a timetable for paying the December 2011 outstanding amount of $929,055 by end of April 2012, the January 2012 invoices in the amount of $4,457,756.50 by end of May, and the February 2012 invoices in the amount of $4,568,097 by end of June, “subject to further on‑going checking and verification” for the January and February invoices. It was stated that all amounts not verified would be disputed. 11.On 19 April, SNE gave a cheque to Chim Kee for the December 2011 amount of $929,055. Later, on the same day, Chim Kee replied to SNE that the proposed payment schedule was not acceptable and asked SNE to certify the payment amount up to date and settle all outstanding payments immediately. 12.On 23 April, SNE wrote to Chim Kee urging it to be “more sensible and accommodating in the circumstances, especially when [Chim Kee’s] ultimate payment within a reasonable time is not in doubt”. Chim Kee swiftly replied on 24 April, stating:
13.On 27 April, following a meeting with Hsin Chong, SNE wrote to request Hsin Chong:
14.On 2 May, Chim Kee wrote to SNE stating:
15.On 17 May, with funds advanced from Hsin Chong, SNE paid $8,086,545.50 to Chim Kee, comprising the two sums of $4,389,296.50 and $3,697,249 for January and February respectively. Chim Kee’s receipts for these amounts stated, however, that the first sum was for payment of “11–12/2011, 1/2012 — partial” and the second sum “2/2012 — partial”. 16.On 23 May, Hsin Chong, SNE and Chim Kee entered into what has been called the Tri‑partite Rental Arrangement (“TRA”). The TRA was typewritten on Chim Kee’s letterhead and signed by Chim Kee and countersigned by SNE and Hsin Chong in acceptance and acknowledgment. It was headed “Rental Arrangement” and provided:
Events after TRA 17.Subsequently, SNE obtained funds from Hsin Chong and, on 13 June, SNE paid Chim Kee $3,841,751 by cheque for the March invoices and remitted $3,758,249 to Chim Kee by bank transfer for the April invoices (totalling $7.6 million). Chim Kee’s stance was that these were only partial payments of the invoices. 18.On 26 June, Chim Kee issued an ultimatum to SNE (copied to Hsin Chong) referring to three “outstanding issues”, saying SNE still owed Chim Kee:
Item (3) seems to be a reference to an agreement drafted by Chim Kee on about 23 May for the hire period of all the equipment being used at Site 802 to be extended for at least 6 months from 1 June 2012. It had not been signed by SNE. Chim Kee’s letter continued to state:
19.On the same day, Hsin Chong served on SNE a notice of breach of sub‑contract 8800/11 on the basis that SNE had failed to use the interim payments from Hsin Chong to pay SNE’s sub-contractors. Hsin Chong threatened to withhold further interim payments and use such money to settle directly the payment or wages of the workers for and on behalf of SNE pursuant to the sub‑contract. Hsin Chong also expressed concern that some equipment such as rotators might be withdrawn by SNE’s sub-contractors, which was, it would seem, a reference to Chim Kee. 20.On 26 June, SNE wrote to Hsin Chong asking for special payment “through SNE account” to settle Chim Kee’s May invoices. 21.On 28 June, SNE replied to Chim Kee. SNE stated that the March and April amounts were certified at $3,841,751 and $3,355,495 respectively. It signed some of the quotations as requested by Chim Kee. It asked Chim Kee to issue a new rental agreement and SNE would propose their estimated hire period. 22.On 29 June, Chim Kee replied that the amounts certified by SNE for March and April 2012 were partial payments only and asked SNE to certify all outstanding invoices of March and April and arrange for payment immediately. Chim Kee’s termination 23.Finally, on 3 July, following a meeting between their representatives, Chim Kee gave notice to SNE that it was terminating the hire arrangements, stating:
SNE took the position that Chim Kee was not entitled to terminate the MHA and that this purported termination was a wrongful repudiation. 24.On the same date, Hsin Chong issued a letter to SNE and took over SNE’s sub‑contracts works, saying:
25.There followed what the judge described as a “period of uncertainty” and “period of chaos” until 26 July.[2] On the next two days Hsin Chong took over the site. SNE’s workers were apparently stopped from entering it. They staged a protest and it appears that the steps for Hsin Chong formally to take over were halted after 5 July. 26.SNE claimed that when their workers went back to the site on 6 July, they found that Chim Kee’s workers were deliberately operating slowly or simply refused to work. This went on for several days. 27.Meanwhile, at noon on 6 July, Mr Stephen Wai of SNE together with SNE’s solicitor had a meeting with Mr James Tang of Chim Kee and Mr Frankie Lam of Hsin Chong. There was a dispute about what was agreed at the meeting, and the judge found that Chim Kee only agreed to “stand by” and that there was no agreement to resume work for SNE. 28.On 10 July, Chim Kee’s solicitors sent SNE’s solicitors a statement of account showing an outstanding amount of $9,192,474.50 up to end of June. 29.On 11 July, SNE wrote to Hsin Chong (copied to Chim Kee) stating that it accepted Chim Kee’s termination and would mobilize new resources immediately to carry on the sub‑contract works. Thereafter it was SNE’s case that it asked Chim Kee to demobilize its machinery and vacate the site but Chim Kee did not do so and obstructed SNE’s workers in performing their work. Chim Kee’s position was that it needed a demobilisation plan and the consent of Hsin Chong and/or MTRC in order to remove the machinery. On 24 July, SNE obtained an ex parte injunction from the High Court to require Chim Kee to remove its machinery out of the site. The order as amended was served on 25 July (though it was later discharged on 10 August on the grounds of non‑disclosure and lack of justification for an ex parte application). 30.On 26 July, Hsin Chong issued a notice under sub‑contract 8800/11 to take over part of the sub‑contract works, and divided the site into two areas: a smaller working area for SNE and the larger remaining area for Hsin Chong. It appears that pursuant to the injunction, Chim Kee soon removed its machinery from SNE’s part of the site. 31.On 1 August, Chim Kee presented a petition to wind up SNE on the basis of an outstanding balance of $9,192,474.50. This was subsequently struck out by the court in May 2013 on the ground of potential cross‑claims and substantial disputes over the debt, with SNE having indeed issued the writ of summons in these proceedings in October 2012. 32.On 11 and 20 September 2012, Hsin Chong served on SNE notices of termination of sub‑contracts 8664/10 and 8800/11 respectively with immediate effect. There are still ongoing disputes between SNE and Hsin Chong arising from the sub‑contracts which are apparently the subject matter of arbitration proceedings. Storage of SNE’s equipment in Chim Kee’s workshop 33.Separately, since September 2010, SNE had had a separate, discrete agreement with Chim Kee for the storage of SNE’s equipment in Chim Kee’s workshop in Fanling. SNE terminated this agreement on 1 March 2012 and asked for the return of the plant and machinery stored. SNE claimed that Chim Kee had wrongfully detained them while Chim Kee said SNE had refused to pay a lifting fee for the removal of the machines. III. The parties’ claims 34.At trial, SNE claimed the following:
35.Chim Kee’s counterclaims were as follows:
IV. The judgment below 36.The judge, having rejected the argument of waiver[3] (see §7 above), held that the payment terms in Chim Kee’s quotations had not been varied by the TRA. He did this on two grounds. First, the TRA provided only an alternative payment method — a “second string to the bow” or “safety net”, but not a substitution of the existing payment terms. As a result, “the primary obligation to pay Chim Kee remained on SNE”.[4] Secondly, the judge held that no consideration flowed from SNE for any variation of its payment obligation.[5] 37.The judge found that as at 3 July 2012, $4,993,916 was outstanding for pre‑June invoices and this sum together with the June invoices remained unpaid. He found that SNE had not proved that Chim Kee’s termination was anything other than a valid exercise of its right to terminate the MHA pursuant to clause 5(b) of the General Conditions of Hire.[6] 38.On SNE’s claim for breach of implied term based on the events between 3 and 26 July 2012, the judge was prepared to find that the implied term contended for by SNE existed but held it did not survive termination of the MHA on 3 July 2012.[7] He found that, in any event, it was reasonable for Chim Kee to require a demobilization plan and the consent of Hsin Chong and MTRC’s Engineer for removal of the machinery.[8] He concluded that SNE failed to prove that any loss it suffered from the events of 4 — 26 July was Chim Kee’s liability. Finally, the judge also held there was insufficient evidential basis for the amounts claimed by SNE in this regard ($1,575,934 and $1,330,691).[9] 39.The judge rejected SNE’s claim for overpayment, dismissing it as a “post‑termination afterthought”. He gave various reasons for concluding that the palm prints method relied on by SNE was flawed and not a reliable method.[10] 40.As to SNE’s claim for damages for wrongful detention of its equipment in the Fanling workshop, the judge found that Chim Kee’s insistence on the provision of an indemnity against injury or loss before SNE could arrange its own collection was “unduly obstructive”.[11] He dismissed SNE’s claim, however, because SNE had admittedly not paid any of the invoices for renting alternative equipment which made up the substantial part of the $666,280 claim and there was no other evidence as to quantum.[12] 41.The judge also dismissed SNE’s conspiracy claim both on the ground that the pleading was deficient and that the facts did not support the alleged conspiracy.[13] 42.As for Chim Kee’s counterclaims, the judge upheld its claim for outstanding hire charges for May and June 2012 and an unpaid pre‑May balance. He adopted Chim Kee’s calculation of the pre‑May balance at $897,747, but adopted the figure of $7,218,010, which was the median between the amount invoiced by Chim Kee ($7,986,827) and the amount certified by SNE ($6,449,193), for the May and June charges.[14] He declined to award any July 2012 hire charges to Chim Kee.[15] 43.For the storage of equipment in Fanling, the judge allowed Chim Kee a sum of $250,000 as storage charges from March to October 2012 (reduced from $387,900 claimed by Chim Kee) and disallowed any charges after October 2012.[16] 44.The judge rejected Chim Kee’s counterclaim for the loss of or damage to the casings, guard houses and soil tank.[17] V. The scope of the appeal and cross‑appeal 45.The grounds for SNE’s appeal are set out in its Supplementary Notice of Appeal. Broadly speaking, SNE contends:
46.Ground 6 is not pursued. Ground 9 raises a complaint that the judge made certain findings that concern the dispute between SNE and Hsin Chong. However, as Mr C Y Li SC, who appeared for SNE on this appeal (but not below), admitted, this ground is not being relied upon to impugn any of the orders made by the judge or in support of any relief sought from this court. It follows that, on settled practice, there is no basis for us to entertain this ground: Lake v Lake [1955] P 336. We may add that it seems to us that the judge carefully took it upon himself to refrain from making any findings in relation to the dispute between SNE and Hsin Chong as far as possible. 47.Chim Kee’s cross‑appeal is limited to the quantum of the May and June hire charges. It contends that the judge was wrong to take the median between the invoiced amount and the amount certified by SNE, and should have simply adopted the former (see §42 above). This, if successful, would increase the judgment on the counterclaim by a principal amount of $768,817. 48.We discuss these issues in turn below. VI. Termination of MHA by Chim Kee 49.While Chim Kee’s letter of termination referred to SNE’s failure to provide any commitment on repayment, compensation for damaged equipment and rental period of equipment, the only pleaded basis for Chim Kee to terminate the MHA on 3 July 2012 was SNE’s failure to pay outstanding hire charges. Both parties proceeded in the court below and in this appeal on the basis that the termination was pursuant to clause 5(b) of the General Conditions of Hire, not for any repudiatory breach by SNE whether by default in payment or otherwise, and that the relevant question is whether Chim Kee was entitled to invoke clause 5(b). Whether invoices were due 50.Mr Li submitted that Chim Kee was not entitled to ask for $9,192,474.50 as it did as at 3 July 2012 because this amount covered invoices issued in June 2012 which had not become payable as they were less than 30 days old. The point is not in the notice of appeal but, in any event, as Mr Ian Pennicott SC, who appeared for Chim Kee, pointed out, the judge found there was a pre‑May balance of $897,747 outstanding and there were also the May invoices which were issued on 31 May 2012 and hence more than 30 days before 3 July. Termination of MHA and TRA — Ground 1 51.Mr Li’s main submission on termination centres around the TRA. There are two points raised: what the TRA meant and whether it was supported by consideration. 52.The meaning of the TRA, being a written agreement, is to be ascertained as a matter of construction of its written terms. We accept that in this exercise the subsequent conduct of the parties is generally not admissible: James Miller & Partners Ltd v Whitworth Street Estate Ltd [1970] AC 583 at 603; Marble Holding Ltd v Yatin Development Ltd (2008) 11 HKCFAR 222, §22; The New China Hong Kong Group Ltd (in liquidation) v AIG Asian Infrastructure Fund LP (unrep, CACV 24/2008, 12 February 2009), §78. Insofar as the judge derived support for his construction of the TRA from SNE’s request made in June 2012 to Hsin Chong for funds to enable SNE itself to pay Chim Kee, this was impermissible.[18] 53.There was some uncertainty as to what, on SNE’s case, the precise legal effect of the TRA was. SNE’s Reply pleaded that under the TRA, payment to Chim Kee was “guaranteed” by Hsin Chong. Mr Li submitted, however, that the TRA provided for “vicarious performance” of SNE’s payment obligation by Hsin Chong, in the sense in which that phrase is used in Chitty on Contracts (32nd ed), Vol 1, §19–082:
54.As Lewison LJ stated in the English Court of Appeal’s decision in North v Brown [2012] EWCA Civ 223 (para 8), vicarious performance is “a means by which one party to a contract performs his own obligations under that contract. It is not a means by which anyone else has rights under the contract, let alone becomes party to it.” An arrangement purely for vicarious performance does not in any way alter the rights and obligations between the original contracting parties. It seems to us that SNE’s case, as advanced in this appeal, is not limited to vicarious performance as such because it contends that Hsin Chong was a party to the TRA and undertook certain obligations pursuant to it and the contractual position between SNE and Chim Kee was varied by the TRA. Precisely what obligation Hsin Chong undertook (on SNE’s case) is unclear: counsel’s skeleton stated that Hsin Chong “assumed the responsibility” to pay rental fees to Chim Kee on behalf of SNE, but at the hearing Mr Li, after some vacillation, submitted that while Chim Kee had a right to ask Hsin Chong for payment, it could not sue Hsin Chong if it failed to pay. The final position of Mr Li’s submission, as we understand it, is that the TRA varied the MHA so that, for relevant invoices:
55.In contrast, Mr Pennicott submitted on behalf of Chim Kee that the TRA merely provided another source of payment to Chim Kee and did not absolve SNE’s liability to settle Chim Kee’s invoices. It was for Chim Kee to submit payment application to SNE and this Chim Kee had done. 56.We are prepared to accept that the TRA was prompted by the demands made by Chim Kee since April 2012 and in particular the threat in the letter of 2 May that all services would be stopped at any time unless payment of all outstanding amounts and future rentals was guaranteed. Mr Li submitted that the intention must have been that the TRA was to provide such assurance to Chim Kee so that it could carry on supplying its equipment and operators effectively without any risk of not getting paid. The intention of the parties to the TRA (including Hsin Chong who was not party to the preceding correspondence) must, however, be found in the terms of the contract properly construed in its context and having regard to its commercial purpose. In our view, properly construed, the TRA did not prevent Chim Kee from terminating the MHA pursuant to clause 5(b). 57.First, on its proper construction, it seems to us the arrangement envisaged in the TRA operated prospectively, and did not extend to past invoices. This is in our view evident from the wording of the TRA. It referred to payment for service “for the amount to be certified by SNE”, and amount “to be assessed” by Hsin Chong if SNE “fails to certify within 21 days upon receipt of the payment application”. The language of the TRA is inapt to cover invoices already submitted by Chim Kee, especially those already certified by SNE. 58.As mentioned in §13 above, on 27 April, SNE had already written to ask Hsin Chong to help with payment of Chim Kee’s invoices from January to April “through SNE account” (which seems to mean the provision of funds to SNE to be paid on to Chim Kee), and indicated that the March invoices were being checked by SNE and would be passed to Hsin Chong’s quantity surveyor. The January and February invoices were indeed paid by SNE itself with funds from Hsin Chong on 17 May. As at 23 May, the date of the TRA, the March and April invoices had been issued for over 21 days. There is nothing to suggest that the TRA was intended to replace this arrangement between SNE and Hsin Chong for the March and April invoices. There is no provision in the TRA for the March and April invoices to be “re‑issued” so as to be certified by SNE within the next 21 days or for them to be assessed by Hsin Chong forthwith on the basis that SNE had already failed to certify. 59.On this basis, since the judge found that there was an outstanding balance of $897,747 on the pre‑May invoices (as mentioned in §42 above), as to which there is no appeal, there was plainly “default in payment” of that sum within the meaning of clause 5(b). Indeed, the ultimatum issued by Chim Kee (quoted in §18 above) specifically stated that SNE still owed it “certified invoices and payment of March & April 2012”. On this basis alone, Chim Kee was entitled to exercise the right to terminate the MHA under that clause notwithstanding the TRA. 60.Further, in our view, there is force in Mr Pennicott’s argument that the payment mechanism under the TRA was not inconsistent with the 30‑day payment period prescribed in the quotations or with clause 5(b). Under the TRA, it was for SNE to certify the amount for payment and, if certification was done by SNE in good time, there should be no reason why Hsin Chong could not pay Chim Kee shortly thereafter. It is only where SNE “fails to duly certify within 21 days” that Hsin Chong would have to step in to assess the amount due. Mr Li said Hsin Chong would need a reasonable period of time, say 14 days, to carry out the assessment. This assertion lacks evidential basis since what a reasonable time might be was not investigated at trial. On the terms of the TRA the assessment was to be “based on available information” which tends to militate against any lengthy investigation. We are unable to discern an objective intention of the parties that SNE could, by failing to certify, obtain a longer credit period for payment for Chim Kee’s services. We reject counsel’s contention that the payment period was altered to an “unspecified period following certification by P (within 21 days) or assessment by HC”. In our opinion, there is no foundation to suppose that the 30‑day payment term or clause 5(b) was abrogated or varied by the TRA by necessary implication. 61.As a matter of commercial reality, it can be seen from Chim Kee’s letter of 2 May (§14 above) that it was seriously dissatisfied that SNE could not settle outstanding amounts on time, and was proposing to withdraw its services at any time unless there was some guarantee of payment. The January, February and March invoices were by then overdue in full. While Chim Kee wished to have the benefit of some kind of guarantee in order for it to continue the relationship, we do not think it demonstrated an intention that if future payment was guaranteed it need not be made on time. The TRA gave Chim Kee the requisite assurance so that it would be willing to continue with the existing arrangement with a 30‑day credit period for SNE (equivalent to a longer credit period for services rendered at the beginning of the month since they were only invoiced at month‑end). 62.Thirdly, as explained above, SNE’s submission that the TRA essentially provided for vicarious performance of SNE’s obligations to Chim Kee would suggest that the right of Chim Kee to terminate the MHA under the General Conditions of Hire continued unaltered. Vicarious performance arises from the procurement by one person of another to perform the former’s contractual obligations to a third party. Such an arrangement affects neither the content of the contractual obligations nor the consequences of a breach thereof. 63.Mr Li submitted that Chim Kee should have asked Hsin Chong for payment first before terminating the MHA for default in payment. But, in general, it is for the party who has to perform a contractual obligation to procure vicarious performance of it if he wishes. Insofar as Hsin Chong had by the TRA undertaken an obligation to render vicarious performance, it was for Hsin Chong to pay the amount certified by SNE or assessed by itself if SNE failed to certify. The fact is that for the invoice amounts overdue as at 3 July (ie the balance of the March and April invoices, and the May invoices), SNE had neither itself paid nor procured Hsin Chong to pay Chim Kee direct. There is nothing in the TRA to suggest that Chim Kee must first pursue Hsin Chong for payment before exercising any right to terminate. 64.For these reasons also, we agree with the judge’s conclusion that the TRA did not replace clause 5(b) or the 30‑day payment term. It follows that by 3 July, Chim Kee was also entitled to invoke its right to terminate for default in payment of the May invoices which were issued on 31 May. 65.As to the consideration for the TRA, the issue that has arisen is whether any consideration moved from SNE as the promisee. This question can in our view be answered shortly. Mr Pennicott, rightly in our view, did not press his argument that no consideration moved from SNE. There clearly was consideration because ordinarily it would be for Hsin Chong to make interim payment to SNE under the sub‑contracts and for SNE to pay its own suppliers (unless a relevant clause of the sub‑contracts was invoked by Hsin Chong). If, in accordance with the TRA, Hsin Chong was to pay an invoice of Chim Kee directly, Hsin Chong would deduct that amount from the interim payments to which SNE would otherwise be entitled under the sub‑contracts to receive from Hsin Chong and SNE would lose the benefit of having that amount of cash flow via itself. We would therefore respectfully disagree with the judge on his conclusion that there was no consideration from SNE. In light of the above, however, this is not material to the outcome. Termination of Triangular Force — Ground 7 66.By this Ground SNE complains that the judge was wrong to take into account SNE’s termination of Triangular Force on 27 June 2012 and to hold that, with diminished labour, work on site further deteriorated with more risk of non‑payment to Chim Kee.[19] 67.This was not a pleaded basis for termination of the MHA. Chim Kee’s case at trial was not that SNE had repudiated the MHA or committed an anticipatory breach. Accordingly, we agree that this incident was irrelevant to whether or not the termination was lawful. However, although the judge did mention the incident, he did so as part of the narrative without, in our view, relying on it as a ground for termination of the MHA by Chim Kee. This Ground therefore falls away. Mr Li submitted that in fact the evidence showed that this termination had very limited effect on the site works but it is unnecessary for us to deal with this. Evidence of loss from termination — Ground 10 68.In light of the conclusion above, it is unnecessary to deal with the alleged consequences of unlawful termination. We would nevertheless add that, in our view, SNE’s alleged loss of profit in the sum of $34,061,327.45 said to be caused in part by Chim Kee’s wrongful termination was not properly substantiated at trial. All that was produced was a schedule (Table C annexed to the statement of claim) which simply listed the total amounts of Hsin Chong’s interim payments up to 30 September 2013 and rental fees charged by two Japanese suppliers for equipment detained in the site, with a profit margin figure of 15% applied to the sum of those amounts. Neither the quantity surveyor nor the claims consultant who were said to have prepared the schedule gave any evidence or written explanation of it. VII. SNE’s claim for breach of contract based on events between 3 and 26 July 2012 69.On SNE’s appeal in relation to its claim for breach of an implied term, issues in the following areas arise: (i) whether the implied term survived termination of the MHA; (ii) what was agreed on 6 July 2012; (iii) whether 3 to 26 July 2012 was a period of chaos; (iv) the requirement of demobilisation plan and consent of Hsin Chong and MTRC; and (v) evidence of the loss suffered by SNE. We shall discuss them in turn below. Existence of implied term — Ground 2 70.SNE contended for this implied term in the MHA:
71.The judge was persuaded that such a term may be incorporated as contended for during the term of the MHA but held that there was no such implied term after termination. Although the language of the alleged implied term as pleaded included the period after termination, obviously what the judge meant was that the obligation contended for (ie not to obstruct or cause delay to SNE’s works unreasonably by committing any wilful acts or omissions) existed during the term of the MHA but not afterwards. If there was deliberate obstruction by Chim Kee after termination, the judge said that SNE would have a cause of action, possibly trespass, but not for breach of an implied term. 72.It is important to note that we are not concerned with a narrowly formulated implied term that, for example, required an orderly removal of the machinery as soon as practicable after termination. Instead, SNE contends for a very wide term (i) unlimited in time save perhaps with reference to the duration of the sub‑contracts, (ii) unlimited in the kind of acts or omissions prohibited, (iii) applicable in a situation where the parties are no longer in an owner and hirer relationship, and (iv) which seeks to impose restrictions on Chim Kee’s freedom, after the contract has ended, by reference not to lawfulness but to the elusive test of reasonableness. Such a term is, in our view, neither equitable nor necessary; nor is it obviously what the parties must have intended when Chim Kee started renting machines to SNE in 2010. The term was not necessary to give effect to the reasonable expectations of the parties: Tadjudin Sunny v Bank of America, National Association (unrep, CACV 12/2015, 20 May 2016), §41. Whether assessed on the basis of the five conditions set out by Lord Simon in B P Refinery (Westernport) Pty Ltd v President, Councillors and Ratepayers of the Shire of Hastings (1978) 52 ALJR 20 at 26[20] or the single question posed by Lord Hoffmann in Attorney General of Belize v Belize Telecom Ltd [2009] 1 WLR 1988 at §21,[21] we agree with the judge that no such term was to be implied into the MHA post‑termination. Agreement on 6 July 2012 — Ground 3 73.This Ground concerns what was agreed at a meeting at noon on 6 July 2012. The meeting was attended by Mr Stephen Wai of SNE, SNE’s lawyer Mr Robert Lee, and Mr James Tang of Chim Kee. Mr Frankie Lam of Hsin Chong attended apparently as an observer. 74.SNE wrote after the meeting to record that it had confirmed it would hire Chim Kee’s machinery for another 3 months and Chim Kee had confirmed that it would immediately resume the works and provide continuing service. This was followed by SNE’s solicitors’ letter on the same day saying it was their understanding that Mr Wai and Mr Tang had reached an agreement at the meeting that Chim Kee would cooperate with SNE and resume the works with immediate effect subject to certain confirmation that had since been given. The solicitors requested Chim Kee to resume the works immediately and stated that unless that was done by the following morning, SNE would have no alternative but to terminate Chim Kee’s services. There was also a telephone call between Mr Wai and Mr Tang in the evening after the letters. SNE’s account of the meeting was denied by Mr Tang in an email at 10 am the next day which stated:
75.While Mr Tang appeared to have said in cross‑examination that during the meeting, Chim Kee had agreed to continue to provide services to SNE for a further 3 months[22], in re‑examination he confirmed the account given in his email.[23] The judge accepted Mr Tang’s version of the events. 76.Mr Wai was not called as a witness at trial. Mr Matsumoto, who gave evidence for SNE, claimed that he attended the meeting but that was not what his witness statement or SNE’s solicitors’ contemporaneous letter suggested. In his statement, he only said “an accommodation was apparently reached”. 77.On this evidence and on established principles (see Ting Kwok Keung v Tam Dick Yuen (2002) 5 HKCFAR 336), there is in our view simply no basis to impugn the finding of fact by the judge as to what was agreed or not agreed at the meeting. In any event, nothing really turns on this for there is no separate cause of action pleaded for breach of the agreement on 6 July, and it is common ground that by 11 July any hire arrangement had come to an end. Whether Chim Kee had stood by under SNE’s instructions — Ground 4 78.At §56 of his judgment, referring to the agreement on 6 July, the judge said this:
79.SNE takes issue with the suggestion that it instructed Chim Kee to “stand by”. Instead, it is said, it had repeatedly complained to Chim Kee that its workers were idling or working in deliberately slow motion. The slow operation between 6 and 11 July was relied upon by SNE as a breach of the implied term. We do not think the judge meant that SNE instructed Chim Kee’s workers to stand idly by or to work in deliberate slow motion, which would be contrary to common sense. He was simply referring to his conclusion that he preferred the evidence of Mr Tang on what was agreed at the 6 July meeting. 80.SNE produced photographs and video recordings at trial with a view to showing that Chim Kee’s workers were idle or working in deliberate slow motion between 6 and 11 July. The judge did not make any finding on this allegation. Given our conclusions on the other aspects of the claim for breach of implied term, we decline to make such finding for the first time. “Period of chaos” — Ground 5 81.By this Ground, SNE contends that the judge’s characterisation of the period of 3 to 26 July 2012 as a period of chaos was inconsistent with the evidence. SNE submitted there was no “chaos”: the operation at the site had almost come to a complete halt due to Chim Kee’s refusal to operate the machines up to 11 July and to remove them between 11 and 26 July. It seems to us that this is an argument on semantics. By that expression, the judge probably meant no more than that it was a period during which the people involved did not know with any certainty what their position was. 82.Plainly a lot of disputes arose during this period.
83.SNE complained that the judge failed to make findings as to what the disorder was and whose responsibility it was. With respect, this is not a fair criticism. The judge did find that it was not proved to be Chim Kee’s responsibility, and that Chim Kee did not breach any duty in asking for demobilisation plan and consent for the exit of its machinery,[24] which we discuss under the next heading. This was all that was required of him. The judge was careful not to intrude unnecessarily into the dispute between SNE and Hsin Chong. Demobilisation plan and consent — Ground 8 84.This Ground concerns the responsibility for the impasse during the period from 11 to 26 July. On either party’s case the MHA had come to an end by this time. The question was how Chim Kee’s machinery was to be removed out of Site 802. Chim Kee did not remove it immediately after 11 July. It is not in dispute that the continued presence of its large and heavy machines occupied space at the site and thereby obstructed SNE’s work. Chim Kee said it was unable to remove them because SNE had failed to provide a demobilisation plan and obtain consent from MTRC or Hsin Chong, whereas SNE claimed that Chim Kee was in breach of the implied term by failing to remove its machinery thereby causing obstruction to SNE’s work on the site. The issue is academic given our conclusion that the implied term contended for did not exist. 85.Even assuming the implied term continued to apply during this period, because of the way in which it is framed, the issue is whether Chim Kee acted unreasonably in requiring from SNE a demobilisation plan and consent before removing its machines from the site. On this question, the judge concluded:[25]
86.Mr Li argued SNE had no contractual duty to provide a demobilisation plan, and that Chim Kee had the duty to arrange for dismantling. In our view, Mr Pennicott is right in submitting that whether Chim Kee acted unreasonably or otherwise is a finding of fact. The judge did not determine as a matter of law whether, as between Chim Kee and SNE, there was any contractual requirement of a demobilisation plan or third party’s consent. 87.The provisions of the main contract and the sub‑contracts nevertheless have a bearing on the question of reasonableness. Clause 91.6 of MTRC’s main contract with Hsin Chong stipulated:
88.Mr Li argued that “Contractor’s Equipment” did not include Chim Kee’s machines. However, “Contractor’s Equipment” was defined in the main contract as:
“Execution of the Works” was in turn defined to mean:
89.Clause 24.7 of SNE’s two sub‑contracts in turn required SNE to comply with the requirements of the main contract as to the bringing on to and removal from the site of Contractor’s Equipment. 90.Without deciding the precise legal rights and obligations under these provisions (as not all relevant parties to them are before us), it seems to us that Chim Kee’s removal of its machines without the Engineer’s consent would at least risk placing Hsin Chong in breach of the main contract and SNE in breach of the sub‑contracts. As Mr Pennicott pointed out, Hsin Chong wrote to SNE on 17 July stating that a demobilisation schedule was required from SNE and on 20 July stating that consent from MTRC’s Engineer was required. MTRC’s position during that time was also that the Engineer’s consent was necessary. If consent under these contracts was necessary, it was in our view at least not unreasonable to think that the person to obtain consent would be the respective contracting parties under these contracts. In these circumstances, there is, in our view, no basis to disturb the judge’s finding of fact that it was reasonable for Chim Kee to require a demobilisation plan as well as MTRC’s and Hsin Chong’s consent. In the language of the alleged implied term, Chim Kee did not, by requiring them, “obstruct or cause delay to SNE’s works unreasonably”. Evidence of loss from breach of implied term — Ground 10 91.SNE complains that the judge failed to deal at all with the quantum of its claim for damages for breach of the implied term. What the judge actually said was this:[26]
92.These are the 2 amounts pleaded as losses suffered by SNE as a result of the breach of implied term during the period up to 26 July. The first figure is described in the statement of claim to be for additional hiring and depreciation of cranes and rotators provided by other suppliers. The second figure is said to be further loss in relation to hiring and depreciation on other equipment and labour and maintenance costs. Two tables of calculation (A and B) were attached to the statement of claim. 93.The only “evidence” in support of these two tables is Mr Matsumoto’s statement[27] which simply said that the slow operation and idling of Chim Kee’s machinery on the site
94.No evidence has been called to explain the tables which are far from self‑explanatory. Mr Li said that in fact Table A listed only hire charges, not depreciation. Further, as Mr Li accepted, quite inexplicably none of the supporting documents had been produced in discovery or put in evidence. In these circumstances, we entirely agree with the judge that these tables could not be treated as proper evidence of loss. VIII. SNE’s claim for wrongful detention of equipment — Ground 11 95.As to SNE’s separate agreement for the storage of its own equipment at Chim Kee’s workshop (see §33 above), there is no dispute that SNE terminated the agreement in March 2012, that SNE managed to retrieve part of its equipment from Chim Kee’s workshop only in June 2012 and that the remainder has still not been removed. 96.SNE submitted that the judge was wrong to find its first request for collecting its equipment was made on 9 July 2012. In fact, SNE had written to Chim Kee on 1 March 2012 stating:
97.On 12 March, SNE sent over a checklist of its equipment. On 21 March, SNE wrote to Chim Kee stating:
98.On 23 March, SNE sent an email to Chim Kee saying it would like to pick up the tools and machinery as soon as possible and asked Chim Kee to confirm the date. On 24 March, SNE said it would start moving out the materials the following week and asked for Chim Kee’s assistance. Chim Kee did not oblige, possibly because of some payment issues relating to Site 820. 99.On 4 May, SNE wrote again, “strongly” requesting Chim Kee to release its equipment from the storage yard immediately. On 19 May, SNE wrote to say it would start moving out its properties on 22 May. When Chim Kee replied it was busy on 22 May, SNE proposed 24 May. To accommodate Chim Kee, this was further deferred to 29 May. Eventually, although SNE sent 4 trucks and 5 workers to the workshop on that day, Chim Kee said the removal work could not be done. After some further complaint and correspondence, SNE finally managed to retrieve part of its equipment in storage there on several days in June. 100.Unfortunately, as Mr Pennicott informed this court, none of the above material was drawn to the judge’s attention at trial because the focus was on SNE’s claim for damages for wrongful detention the bulk of which was said to accrue from July 2012 onwards. As a result, the judge stated, erroneously in fact, that the first request to recover the equipment was made by SNE on 9 July. 101.SNE did make a request on 9 July to collect the equipment on 10 July. By then, of course, the parties’ relationship had almost completely broken down. Chim Kee replied that the yard was very busy and asked SNE to arrange another day. SNE proposed 11 July but, as far as we can see, there was no reply from Chim Kee. 102.On 24 September, SNE wrote again and proposed a time in early October. Finally, a joint inspection took place on 19 October 2012, but Chim Kee asked for a lifting fee of $50,000, which SNE refused to pay (though Chim Kee said a representative of SNE had agreed to pay it). The judge was inclined to think that the fee of $50,000 was not unreasonable, but this was based on an erroneous assumption that a previous fee of $35,700 had been paid for a similar exercise.[28] In further correspondence, SNE refused to pay the lifting fee and demanded compensation for wrongful detention of its plant and machinery, while Chim Kee asked SNE to pay for storage fees since March 2012. 103.On 8 December, Chim Kee wrote that SNE could arrange for its own workers to retrieve the equipment stored on condition that, if SNE was unwilling to pay the lifting fee, it provided an indemnity from a “financially solid company” for any loss or injury caused. At trial, the judge found Chim Kee’s demand for an indemnity to be “unduly obstructive” and an “unnecessary restriction” because the risk of loss and damage to Chim Kee from SNE’s removal of its own equipment was negligible.[29] His disapproval of Chim Kee’s conduct was reflected in his rejection of Chim Kee’s claim for storage charges after October 2012. 104.On 10 December, SNE offered to pay a lifting fee of $4,800 per day based on past rates charged by Chim Kee. At trial, Mr Tang of Chim Kee admitted that it was a reasonable daily fee for the hire of a crane. Nevertheless, by letter of 21 December, Chim Kee insisted on $50,000 or an indemnity. The matter remained unresolved. In 2013, Mr Tang raised the lifting fee demanded to $100,000, which was admittedly unreasonable, because he felt “fed up and angry”. 105.On the evidence, there is in our view justification for SNE’s complaint that it had been wrongfully denied access to its equipment. There was, however, no claim for specific delivery of the equipment. SNE’s sole claim was for damages. 106.SNE claimed that, as a result of Chim Kee’s wrongful detention of its property, it had to rent alternative equipment, and incurred $666,280 up to 30 November 2012, and $116,236 per month thereafter. Mr Matsumoto’s statement[30] did not elaborate on how the loss was incurred. There was a letter from SNE dated 3 December 2012 attaching a schedule of the expenses said to have been incurred by SNE together with some invoices in Japanese. However, Mr Matsumoto admitted in his oral evidence that the hire charges of alternative equipment had not been paid. As for the administration fee of $20,000 per month, there was simply no explanation or other evidence to substantiate it. In the absence of proper evidence of loss and damage, the judge’s decision to dismiss SNE’s claim cannot, in our view, be faulted. 107.On the other hand, we think that SNE is right in submitting that the judge should not have awarded $250,000 to Chim Kee as storage charges from March to October 2012. It was common ground that the storage contract was terminated on 1 March 2012 so that, as accepted by Mr Pennicott, the award could only be a quantum meruit based on restitution. But quite apart from the point that no such claim was pleaded in the counterclaim, in the circumstances there was in our view hardly any benefit conferred on SNE in having its goods kept (against its will) by Chim Kee for the period up to October 2012. The judge made the order without taking account of SNE’s repeated unsuccessful attempts to retrieve its equipment since March 2012. We would therefore allow this part of the appeal and set aside the award of $250,000. IX. Conspiracy claim — Grounds 12 and 13 108.SNE’s conspiracy claim was pleaded as follows:
109.Paragraphs 12 to 15 of the statement of claim pleaded Chim Kee’s termination of the MHA while paragraphs 24 to 37 pleaded the various matters during the period from 3 to 26 July 2012 that SNE complained of, such as the idling and slow operation of the machines and the failure to remove them. Only one act of Hsin Chong was pleaded, which was a letter of 18 July 2012 threatening to terminate the two sub‑contracts within 7 days on the ground that SNE had failed to proceed with the works with due diligence. 110.As Ma CHJC (as he then was) stated in Pido v Compass Technology Co Ltd [2010] 2 HKLRD 537, a plea of conspiracy must set out the agreement, the means (whether lawful or unlawful), the intention (predominant or otherwise), the pursuant acts and the damage caused. We agree with the judge that SNE’s pleading failed to meet the requirements. Nor can we see any overt act pleaded sufficient to support the allegation of conspiracy: Aktieselskabet Dansk Skibsfinansiering v Wheelock Marden & Co Ltd [1994] 2 HKC 264. 111.Furthermore, whether or not there was a conspiracy is a matter of fact. The judge, who had had the opportunity of seeing Mr Tang of Chim Kee and Mr Lam of Hsin Chong as witnesses, found against it. In our judgment, SNE has not come near to showing any ground on which such a finding can be disturbed by this court. 112.In their skeleton argument, counsel for SNE set out the following matters which, they submitted, gave rise to an “irresistible” inference of a conspiracy between Chim Kee and Hsin Chong:
113.In our view these matters, whether taken singly or in combination, do not support the inference sought. No one could deny that Hsin Chong had an interest in the progress of the pile removal works and its own ability to honour its obligations with MTRC under the main contract. The listed events are at least equally consistent with an alternative, innocent explanation, namely, that Chim Kee and Hsin Chong were doing what each of them independently considered to be in its own best interests in a situation where, as the judge said, “a serious problem requiring urgent resolution was developing”.[31] X. Chim Kee’s cross‑appeal 114.As stated in §42 above, for outstanding hire charges for May and June 2012 the judge adopted the median between the amount invoiced by Chim Kee and that certified by SNE, though he did not give any reason for this approach. Mr Pennicott submitted that since the judge had rejected SNE’s overpayments claim on the ground that the palm prints method was unreliable, he should have held that SNE was bound to pay the May and June hire charges in the amounts stated in Chim Kee’s invoices, without taking account of SNE’s figures at all. 115.Relying on Mr Matsumoto’s evidence, Mr Li submitted that the May and June invoices were not certified by SNE using the palm prints method and that the basis for SNE’s certification of the May and June invoices was not investigated at trial. 116.In our view, not much weight can be placed on Mr Matsumoto’s evidence on that point since the checking was done by SNE’s quantity surveyor rather than him. Further, as Mr Pennicott pointed out, SNE’s Reply referred to the alleged overpayment of invoices for many months from January 2011 to April 2012 calculated by reference to the amounts assessed and certified by SNE in accordance with the palm prints method and went on to plead that Chim Kee also overstated the amount of hire and time claimed in the invoices for May and June 2012. Moreover, SNE’s letter dated 17 September 2012 alleged that Chim Kee had overstated the quantity of overtime works by reference to the difference between the records submitted and the site entrance records generated by the palm prints machines. The letter stated that the deduction on this head from April to June alone was some $1.7 million. 117.In these circumstances, it seems to us a compelling inference arose that the May and June figures certified by SNE were based on the palm prints method. The judge did not explain why he took into account SNE’s certified figures for May and June. We are driven to the conclusion that the judge’s use of a median figure between the invoice amounts and the figures certified by SNE was inconsistent and incompatible with his rejection of the palm prints method as fundamentally flawed. We would therefore allow the cross‑appeal. XI. Disposition 118.For the foregoing reasons:
119.While SNE has succeeded in setting aside the storage fees award, it is a discrete and relatively minor part of the appeal. It has lost on the major parts of its appeal. We would make a costs order nisi that SNE do pay Chim Kee 80% of the costs of the appeal. As for the cross‑appeal, since counsel agreed that costs should follow the event, there will be an order that SNE do pay Chim Kee the costs of its cross‑appeal. There will be a certificate for two counsel.
Mr C Y Li SC and Mr Billy Kwan instructed by Chong & Yen, for the Plaintiff/Appellant Mr Ian Pennicott SC and Mr Joseph Wong instructed by Tsui & Co., for the Defendant/Respondent [1] Judgment, paras 18–24 [2] Judgment, paras 43, 50, 55, 64, 70 [3] Judgment, paras 18–24 [4] Judgment, paras 29‑30 [5] Judgment, para 30 [6] Judgment, paras 33–41 [7] Judgment, paras 47–49 [8] Judgment, paras 57–66 [9] Judgment, para 68 [10] Judgment, paras 72–78 [11] Judgment, para 83 [12] Judgment, para 85 [13] Judgment, paras 98–105 [14] Judgment, paras 42 & 108 [15] Judgment, paras 69–71 [16] Judgment, paras 84 & 86 [17] Judgment, paras 87–91 [18] Judgment, para 31 [19] Judgment, para 40 [20] “(1) it must be reasonable and equitable; (2) it must be necessary to give business efficacy to the contract, so that no term will be implied if the contract is effective without it; (3) it must be so obvious that ‘it goes without saying’; (4) it must be capable of clear expression; (5) it must not contradict any express term of the contract.” [21] “… in every case in which it is said that some provision ought to be implied in an instrument, the question for the court is whether such a provision would spell out in express words what the instrument, read against the relevant background, would reasonably be understood to mean … [T]his question can be reformulated in various ways which a court may find helpful in providing an answer — the implied term must ‘go without saying’, it must be ‘necessary to give business efficacy to the contract’ and so on — but these are not … to be treated as different or additional tests. There is only one question: is that what the instrument, read as a whole against the relevant background, would reasonably be understood to mean?” [22] E/1114 [23] E/1133 [24] Judgment, para 66 [25] Judgment, para 66 [26] Judgment, para 68 [27] At para 112, p 39 [28] Judgment, para 82 [29] Judgment, para 83 [30] At para 136, p 44 [31] Judgment, para 104 |
Cases cited in this judgment
Other judgments that cite this case
Further hearings and rulings under CACV 101/2016